Terms and Conditions

1. Legal Compliance

You agree to comply with all applicable local, national, and international laws and regulations when using our services. This includes but is not limited to:

• • Building codes and regulations applicable to kitchen installations
• • Health and safety requirements for commercial food preparation facilities
• • Import regulations and customs requirements for equipment sourcing
• • Employment and workplace safety regulations if applicable

2. Information Accuracy

You are responsible for providing accurate, complete, and current information when engaging our services. This includes project requirements, budget constraints, timeline expectations, and any site-specific conditions that may affect equipment selection or installation. Inaccurate or incomplete information may compromise the quality and suitability of our recommendations.

3. Decision-Making Authority

You confirm that you have the authority to make decisions regarding the kitchen projects for which you engage our services. If you represent a business entity, you warrant that you are authorized to bind that entity to agreements with Culinar.

4. Professional Advice Limitations

While we provide professional guidance on kitchen equipment selection and planning, you acknowledge that:

• • Final decisions rest with you as the client
• • You should consult licensed professionals (architects, engineers, electricians, plumbers) for technical specifications and installations
• • We do not provide legal, financial, or tax advice
• • Equipment specifications should be verified with manufacturers

5. Prohibited Conduct

You agree not to engage in any conduct that:

• • Violates any applicable law or regulation
• • Infringes intellectual property rights of Culinar or third parties
• • Transmits harmful content or malicious software
• • Attempts to interfere with the proper functioning of our website
• • Uses our services to harm, threaten, or harass others

6. Age Requirements

Our services are intended for adults aged 18 or older who are authorized to make business or personal purchasing decisions. By using our services, you confirm that you meet these requirements.

1. Service "As Is"

Our website and services are provided on an "as is" and "as available" basis. We make no warranties, express or implied, regarding the accuracy, completeness, reliability, or suitability of any information or services provided. To the maximum extent permitted by law, we disclaim all warranties including but not limited to warranties of merchantability, fitness for a particular purpose, and non-infringement.

2. Professional Judgment

While we exercise professional judgment and care in our recommendations, we cannot guarantee specific outcomes or results. Kitchen equipment performance depends on numerous factors including but not limited to proper installation, maintenance, operator skill, usage patterns, and environmental conditions. Your satisfaction with equipment choices may vary based on individual preferences and operational requirements.

3. Third-Party Equipment

When we assist with equipment sourcing, we coordinate with third-party manufacturers and suppliers. We make reasonable efforts to verify equipment specifications and supplier reliability but are not responsible for:

• • Manufacturing defects or equipment failures
• • Shipping delays or damage during transit
• • Manufacturer warranty terms or claims
• • Changes in equipment availability or specifications

Equipment warranties are provided by manufacturers according to their terms. We assist with warranty coordination but do not extend our own warranty on third-party equipment.

4. Limitation of Liability

To the maximum extent permitted by applicable law:

• • Culinar shall not be liable for any indirect, incidental, special, consequential, or punitive damages arising from or related to your use of our services
• • This includes but is not limited to lost profits, business interruption, loss of data, or cost of substitute services
• • Our total liability for any claims related to our services shall not exceed the fees paid by you for the specific service giving rise to the claim
• • These limitations apply regardless of the legal theory (contract, tort, strict liability, or otherwise)

5. Force Majeure

We are not liable for any failure or delay in performance caused by circumstances beyond our reasonable control, including but not limited to acts of God, natural disasters, war, terrorism, strikes, labor disputes, equipment failures, power outages, internet service disruptions, government actions, pandemic events, or supplier failures.

6. Website Content

Information on our website is provided for general informational purposes. While we strive for accuracy, we make no guarantees about the completeness, reliability, or currency of website content. Technical specifications, pricing, and availability of equipment may change without notice. You should verify critical information independently before making decisions.